Loading...
(A) Good Faith Efforts by Awarding Authorities to Obtain LBE Bids on Prime Contracts. Contract Awarding Authorities shall use good-faith efforts for all Contracts subject to the Discount provisions of this Chapter 14B to solicit and obtain Bids from the broadest possible diversity of LBEs and to ensure that MBEs, WBEs, and OBEs are not arbitrarily excluded from participation. Good faith efforts shall include the following:
(1) Arranging Contracts by size and type of work to maximize the opportunities for LBEs to participate. This includes dividing projects into smaller parts.
(a) As soon as practical before soliciting Bids, Contract Awarding Authorities shall submit Large Contract Proposals to the Director for review. The Director shall determine whether the proposed Contract can be divided into smaller Contracts so as to enhance the opportunity for participation by LBEs. For purposes of this paragraph, "Large Contract Proposals" means any Public Works/Construction Contract estimated to cost more than $5,000,000, any Professional Services Contract estimated to cost more than $1,000,000, and any Commodities Contract with a term greater than one year, including any options to renew or extend.
(b) If the Director determines, after consulting with the Contract Awarding Authority, that the Contract can be divided into smaller Contracts, then the Director and the Contract Awarding Authority shall confer regarding all of the costs and benefits of soliciting the Contract as a single Contract or dividing it into smaller Contracts, including but not limited to the potential for enhanced opportunities for LBE participation as Prime Contractors, the potential for LBE participation as Subcontractors, suitability of procuring the work through Micro-LBE Set-Aside under Section 14B.7(K), relative costs, administrative issues, and any other matters relevant to the accomplishment of the purpose of the subject Contract or Contracts. If, after exchanging information and conferring regarding these issues, the Contract Awarding Authority and the Director are unable to agree on whether to divide the Contract into smaller Contracts or how to divide the Contract, the Mayor or the Mayor’s designee, provided that the designee is not the department head of the Contract Awarding Authority, shall resolve the matter.
(2) Outreaching to all LBEs with appropriate certifications for the work or services to be performed to solicit their interest in specific contracting opportunities when not impracticable to do so, and encouraging LBEs to attend prebid meetings.
(3) Posting contracting opportunities on the Department, Office of Contract Administration, and/or other centralized City website, as applicable, with adequate lead time for LBEs to effectively respond to the opportunity.
(4) Providing all Bidders, including LBEss,1
access to adequate information about the plans, specifications, and requirements of the proposed Contract.
(5) Using the services of community and contractors' groups to assist in the recruitment of LBEs.
(6) For Professional Services, General Services, Architect/Engineering and Commodities Contracts, the estimated cost of which exceeds $10,000 but is less than the Minimum Competitive Amount, or for Public Works/Construction Contracts, the estimated cost of which exceeds $10,000 but is less than the Threshold Amount, Contract Awarding Authorities are not required to undertake the good faith efforts steps set forth in Section 14B.7(A)(3) when it is impracticable to do so.
(B) Best Efforts on Contracts Not Otherwise Subject to this Chapter. Contract Awarding Authorities shall adopt the same good faith efforts set forth in Section 14B.7(A) for the award of leases, franchises, concessions, and other Contracts not subject to the Discount provisions of this Chapter 14B, unless impracticable to do so. At a minimum, Contract Awarding Authorities shall notify LBEs that are certified to perform the work contemplated in a Contract and solicit their interest in the Contract. For Contracts with mixed local and federal and/or State funding subject to Section 14B.18(A) where the federal or State laws, rules, or regulations prevent the implementation of LBE preference programs, Contract Awarding Authorities are encouraged to the extent feasible to break up or create distinct portions of work, as applicable, to isolate any local funds so as to maximize the ability to implement this Chapter 14B’s programs.
(C) Equal Opportunity in Prime Contracting. Contract Awarding Authorities shall ensure that all aspects of their contracting process are transparent, fair, and do not arbitrarily disadvantage or discriminate against LBEs or any other business or Person on any basis prohibited by law. Contract Awarding Authorities shall document their selection processes as required by the Director to monitor and ensure compliance with this provision. The Director shall report any contracting process by a Contract Awarding Authority that the Director believes may be discriminatory in nature to the Human Rights Commission.
(D) Contracts Subject to Prime Bid Discounts. Contract Awarding Authorities shall apply Discounts to all Contracts the estimated cost of which exceeds $10,000 and is less than $10,000,000, except that the Bid Discount provisions applicable to SBA-LBEs shall apply only to Contracts (other than Commodities Contracts) with an estimated cost of no less than $400,000 and no greater than $20,000,000, and to Commodities Contracts with an estimated cost of no less than $400,000 and no greater than $10,000,000. Discounts shall apply to Bids from LBE Prime or Joint Ventures only where the LBE Prime or Joint Venture Partner will perform a Commercially Useful Function on the Contract. A LBE Prime or Joint Venture whose Bid receives a Discount and who thereafter fails to perform a Commercially Useful Function under the Contract at least equivalent in scope and value to the role represented in its Bid documents may be subject to sanctions as set forth in Section 14B.17(D) for noncompliance with this Chapter 14B.
(E) Amount of Discount. Unless otherwise provided in this Chapter 14B, Contract Awarding Authorities shall apply the following Discounts to each evaluation stage of the selection process, including qualifications, proposals, and interviews:
(1) For Contracts estimated by the Contract Awarding Authority to cost in excess of $10,000 but less than $10,000,000, a 10% Discount to any Bid from a Small or Micro-LBE. If after the application of the Discounts provided for in this Subsection 14B.7(E)(1) or Subsection 14B.7(F) to any Bid from a Small or Micro-LBE, the apparent low Bidder or highest ranking Proposer is not a Small or Micro-LBE, Contract Awarding Authorities shall apply a 5% Discount to any Bid from an SBA-LBE. Contract Awarding Authorities shall apply this 5% Discount to Contracts, except that the 5% Discount for SBA-LBEs shall not be applied at any stage if it would adversely affect a Small or Micro-LBE.
(2) For Contracts estimated by the Contract Awarding Authority to cost in excess of $10,000,000 but less than $20,000,000, a 2% Discount to any Bid from a Small, Micro, or SBA-LBE for Public Works/Construction, Architect/Engineering, Professional Services, or General Services Contracts. Bids from Small, Micro, or SBA-LBEs for Commodities Contracts in excess of $10,000,000 are not eligible for the Discount.
(F) Joint Ventures For Professional Services and Architect/Engineering. Unless otherwise provided in this Chapter 14B, for Contracts estimated by the Contract Awarding Authority to cost in excess of $10,000 but less than $10,000,000, Contract Awarding Authorities shall apply the following Discount to Bids from Joint Ventures with a Small and/or Micro-LBE Joint Venture partner participation on Professional Services and Architect/Engineering prime Contracts:
(1) 5% to a Joint Venture with Small and/or Micro-LBE Prime Contractor participation that equals or exceeds 35% but is under 40%;
(2) 7.5% to a Joint Venture with Small and/or Micro-LBE Prime Contractor participation that equals or exceeds 40%;
(3) 10% to a Joint Venture exclusively among Small and/or Micro-LBE Prime Contractors.
(4) Contract Awarding Authorities shall apply the Discount to each stage of the selection process, including qualifications, proposals, and interviews.
(5) The Contract Awarding Authority shall apply the Discount described in this subsection (F) only to Bids from Joint Ventures, as defined in this Chapter 14B and its duly promulgated Rules and Regulations, on Professional Services and Architect/Engineering Contracts, and only to those Joint Venture Bids where the Director finds that the Small and/or Micro LBE Joint Venture partner (a) will be responsible for, and has sufficient skill, experience, and financial capacity to perform a clearly defined portion of the work, and (b) shares in the Ownership, Control, management responsibilities, risks, and profits of the Joint Venture at least in proportion to the value of its assigned Joint Venture work. The Joint Venture’s Bid must set forth in detail the Small and/or Micro-LBE Joint Venture partner’s portion of the work separately from the work to be performed by the non-LBE Joint Venture partner, and such work must be assigned a commercially reasonable dollar value.
(G) Affidavit.
(1) Each Bidder and Contractor shall be required to sign an affidavit declaring under penalty of perjury its intention to comply fully with the provisions of this Chapter 14B and attesting to the truth and accuracy of all information provided regarding such compliance.
(2) Any Bidder that fails to comply with the provisions of this Chapter 14B in connection with the submission of a Bid may be subject to appropriate sanctions under Section 14B.17(D) whether or not such Bidder is awarded a Contract.
(3) No person shall knowingly make, file or cause to be filed with the City any materially false or misleading statement or report in connection with this Chapter 14B. If the Director has reason to believe that any person has done so, the Director may conduct an investigation, and after notice and a full and adequate opportunity to be heard, may impose appropriate sanctions under Section 14B.17(D), or the Director may refer the matter to an appropriate governmental law enforcement agency.
(H) Additional Requirements.
(1) Each Contract subject to this Chapter 14B shall incorporate by reference, and require the Contractor to comply with, the requirements imposed on Contractors therein. In addition, all Contractors shall incorporate by reference in all subcontracts entered into in fulfillment of a Contract’s subcontracting participation requirement, and require Subcontractors to comply with, all requirements applicable to Subcontractors under Chapter 14B. The Contractor’s compliance with Chapter 14B and Contractor’s Contractor’s1
duty to impose specified requirements in specified Subcontracts are material elements of the City’s agreement to enter into the Contract and failure to comply shall constitute a material breach of contract.
(2) If the Director finds that any Bidder, Subcontractor or Contractor fails to comply with any of the provisions of this Chapter 14B, rules and regulations implementing the Chapter, or Contract provisions pertaining to any LBE, LBE participation, or outreach, such Bidder, Subcontractor, or Contractor shall be liable for liquidated damages for each Contract in an amount up to 25% of the total amount of the Contract or subcontract, as applicable, or $1,000, whichever is greatest, as determined by the Director. The liquidated damages assessed shall be payable to the City upon demand and may be set off against any monies due to the Bidder, Subcontractor, or Contractor from any Contract with the City. Such willful failure to comply with any provisions of this Chapter 14B and the subsequent penalty shall be included in the Contractor’s evaluation report upon completion of the project, if such evaluation is collected.
(3) Contractors and Subcontractors shall maintain all records, including but not limited to such information specified by the Director, necessary for monitoring their compliance with the duties imposed on Contractors under this Chapter 14B, for five years following expiration of the Contract, or, as applicable, Subcontract, and shall permit the City to inspect and audit such records.
(4) During the term of the Contract, Prime Contractors shall fulfill the LBE participation commitments stated in their Bids and memorialized in their Contracts. A Contractor’s failure to achieve the level of LBE subcontractor participation specified in the Contract shall be deemed a material breach of contract.
(5) Prime Contractors shall include in all Subcontracts with a LBE a provision requiring the Prime Contractor to compensate the LBE Subcon- tractor for damages for breach of contract or liquidated damages equal to 5% of the Subcontract amount, whichever is greater, if the Prime Contractor fails to use the LBE Subcontractor as specified in the Bid and Contract unless the Director and the Contract Awarding Authority both give advance approval to the Prime Contractor to sub- stitute the LBE Subcontractor or otherwise modify the LBE commitments in the Bid and Contract documents. It shall be a material breach of contract for a Prime Contractor to fail to include such clause in all Subcontracts with LBEs. This provision shall also state that it is enforceable in a court of competent jurisdiction.
(6) Whenever amendments, modifications, supplements, or change orders increase the total dollar value of the Contract, the Prime Contractor must comply with those provisions of this Chapter 14B that applied to the original Contract with respect to the amendment, modification, supplement, or change order.
(7) Contract Awarding Authorities shall submit to the Director for approval all proposed Contract amendments, modifications, supplements, and change orders that cumulatively increase by more than 20% the total dollar value of all Contracts originally valued at $50,000 or more. The Director shall impose or increase the Subcontracting participation requirement as necessary to reflect additional opportunities for LBE participation from the proposed amendment, modification, supplement, or change order as appropriate.
(8) Prime Contractors and Subcontractors may not engage in any Back Contracting or other work shifting to a lower-tier Subcontract to evade using LBE Subcontractors to perform work or for any other purpose inconsistent with the provisions of this Chapter 14B, or rules and regulations adopted pursuant to this Chapter.
(9) Prompt Payment. For the duration of any Contract subject to LBE participation requirements, the Prime Contractor shall:
(a) Pay its Subcontractors within three working days after receiving payment from the City unless the Prime Contractor notifies the Director in writing within ten working days prior to receiving payment from the City that there is a bona fide dispute between the Prime Contractor and the Subcontractor, in which case the Prime Contractor may withhold the disputed amount but shall pay the undisputed amount. The Director may, upon making a determination that a bona fide dispute exists between the Prime Contractor and Subcontractor, waive this three-day payment requirement. In making the determination as to whether a bona fide dispute exists, the Director shall not consider the merits of the dispute. The Prime Contractor shall submit within 10 working days following receipt of payment from the City, a statement, in a form specified by the Director, attesting that the Prime Contractor has paid all Subcontractors all undisputed amounts from previous City payments; and
(b) Include its Subcontractor’s approved payment requests in any payment application to the City within 30 days of receiving an invoice from an LBE subcontractor.
(I) Reserved.
(J) Waivers. The Director shall waive the Discount provided in Section 14B.7(D), and post all approved waivers online on a CMD website, if:
(1) The Director finds, with the advice of the Contract Awarding Authority and the Office of Contract Administration, that needed goods or services are available from a sole source that is not currently disqualified from doing business with the City; or
(2) For Contracts in excess of $5,000,000, a Contract Awarding Authority establishes that sufficient qualified LBEs capable of providing the needed goods and services required by the Con- tract are not available, or the application of the LBE Discount will result in significant additional costs to the City if the waiver of the Bid Discount is not granted.
(K) Micro-LBE Set-Aside Program.
(1) Each fiscal year, each Contract Awarding Authority, in consultation with the Director, shall set aside the following for award to Micro-LBEs:
(a) Not less than 50% of eligible Public Work/Construction Contracts and
(b) Not less than 25% of Eligible Services/Commodities Contracts.
(2) Contracts under the Micro-LBE Set-Aside Program shall be competitively awarded in accordance with the Administrative Code, except that if (a) fewer than two qualified Micro-LBEs submit Bids, or (b) the Contract Awarding Authority determines that the Contract would not be awarded at a fair market price, then the Contract Awarding Authority may reject all Bids and rebid the Contract outside the set-aside program.
(3) Each Contract Awarding Authority shall include the following information concerning its compliance with the Micro-LBE Set-Aside Program to the Board of Supervisors as part of its annual report under Section 14B.15(B):
(a) Each Eligible Public Works/Construction Contract and, each Eligible Services/Commodities Contract awarded under the Micro-LBE Set-Aside Program, and its dollar amount; and
(b) Each Eligible Public Works/Construction Contract and each Eligible Services/Commodities Contract not awarded under the Micro-LBE Set-Aside Program, accompanied by an explanation as to why each such Contract either was not set aside, or, if set aside, was not awarded under the Micro-LBE Set-Aside Program.
(4) Contracts that are set-aside for award to Micro-LBEs shall not be subject to the subcontracting participation requirement under Section 14B.8. Micro-LBEs that subcontract any portion of a set-aside Contract should subcontract to businesses certified as Micro-LBEs, to the maximum extent possible. Micro-LBEs that subcontract any portion of a set-aside Contract must serve a Commercially Useful Function based on the Contract’s scope of work, and must perform work directly with a value of at least 25% of the total Contract amount.
(L) San Francisco First Program.
(1) Unless otherwise provided in this Chapter 14B, Contract Awarding Authorities shall use the good faith efforts set forth in Section 14B.7(A) to attempt to obtain at least three Bids from Micro or Small LBEs for all Public Works/Construction Contracts estimated to cost in excess of $10,000 but less than the Threshold Amount and all Commodities, Architect/Engineering, Professional Services, and General Services Contracts estimated to cost in excess of $10,000 but less than the Minimum Competitive Amount.
(2) If the Contract Awarding Authority is unable to obtain at least three Bids from Micro or Small LBEs, the Contract Awarding Authority shall prepare a written finding explaining why at least three Bids from LBEs were not obtained.
(M) Prompt payment. The City shall pay LBE Prime Contractors within 30 days of the date on which the City receives an invoice for work performed for and accepted by the City.
(N) Best Value Public Works Contract Discounts. For Contracts authorized under Administrative Code Section 6.74, Contract Awarding Authorities shall apply the applicable Discount to the price or cost portion of the Bid only. No Discount shall apply to the qualifications portion of the solicitation.
(Added by Ord. 92-06, File No. 050784, App. 5/11/2006; amended by Ord. 20-10, File No. 091405, App. 2/10/2010; Ord. 97-10, File No. 100333, App. 5/13/2010; Ord. 8-11, File No. 101006, App. 1/7/2011; Ord. 250-14
, File No. 140999, App. 12/17/2014, Eff. 1/16/2015, Oper. 7/1/2015; Ord. 94-16
, File No. 160225, App. 6/3/2016, Eff. 7/3/2016; Ord. 220-20
, File No. 200949, App. 11/6/2020, Eff. 12/7/2020; Ord. 203-21, File No. 210835, App. 11/12/2021, Eff. 12/13/2021, Oper. 7/1/2022)
CODIFICATION NOTE
1. So in Ord. 203-21.
(A) LBE Subcontracting Participation Requirements. Prior to soliciting Bids, Contract Awarding Authorities shall provide the Director with a proposed job scope for each (1) Public Works/Construction Contract that equals or exceeds 50% of the Threshold Amount, and (2) each Architect/Engineering, Professional Service, and General Services Contract that equals or exceeds 50% of the Minimum Competitive Amount. The Contract Awarding Authority may ask the Director to waive LBE subcontracting participation requirements where it anticipates that there are no subcontracting opportunities or there are not sufficient LBEs available to perform the subcontracting work available on the Contract.
The Director shall set LBE subcontracting participation requirements, including separate Micro-LBE, Small-LBE, and SBA-LBE subcontracting participation requirements when possible, for each such Contract, where appropriate, based on the following factors:
(1) The extent of subcontracting opportunities presented by the scope of the proposed Contract; and
(2) The availability and capacity of LBE Subcontractors certified to provide goods and services required under the scope of the proposed Contract.
Except where the Director determines there are not sufficient Small and Micro-LBEs available to perform the subcontracting opportunities presented by the scope of the proposed Contract, Bidders must list and use only Small and Micro-LBEs to satisfy the LBE subcontracting participation requirement set by the Director. Where the Director determines that there are not sufficient Small and Micro-LBEs available, the Director may authorize Contractors to satisfy the LBE subcontractor participation requirement by using Small, Micro or SBA-LBEs, or may set separate subcontractor participation requirements for Small Micro, and SBA-LBEs.1
For each Contract where the Director sets a LBE subcontracting requirement at less than 20%, the Director shall prepare a written explanation of the details justifying the LBE subcontracting requirement set. The written explanation shall be posted on line as soon as practicable.
(B) Satisfaction of Good Faith Efforts Requirements. At the time of a Bid, all Bidders must meet the LBE subcontracting participation requirement set by the Director, and also must conduct good faith efforts and file evidence of good faith efforts as required in Sections 14B.8(D) and (E) respectively, with the following exceptions:
(1) If LBE subcontracting participation in the submitted Bid exceeds the LBE subcontracting participation requirement set by the Director for the Contract by at least 35%, the Bidder is excused from conducting or documenting its good faith efforts as otherwise required in Sections 14B.8(D) and (E). LBE subcontracting participation shall be determined in this Section 14B.8(B)(1) only, as the sum of all participation by Small and Micro-LBE Prime Contractors, Small and Micro-LBE Joint Venture partners, and Small and Micro-LBE Subcontractors. Participation by SBA-LBE Subcontractors shall count toward LBE subcontracting participation for purposes of determining whether the Bidder is excused from conducting and documenting good faith efforts only if, under Subsection 14B(8)(A), the Director permitted Bidders to list SBA-LBE firms to satisfy subcontracting participation requirements on the Contract.
(2) Where the Director has set LBE subcontracting participation requirements for Public Works/Construction Contracts in an amount less than the Threshold Amount or on Architect/Engineering, Professional Services, or General Services Contracts in an amount less than the Minimum Competitive Amount, Bidders are not required to conduct good faith efforts or to file evidence of good faith efforts as required in Sections 14B.8(D) and (E).
(C) Non-responsive Bids. Bids that do not meet the LBE subcontracting participation requirements set under 14B.8(A) will be rejected as non-responsive unless the Director finds that the Bidder diligently undertook all the good faith efforts required by this Chapter 14B (or that the Bidder is exempt from good faith efforts requirements under Section 14B.8(B)) and that the failure to meet the good faith efforts requirements and/or the subcontracting participation requirements resulted from an excusable error. Bidders must contact a LBE before listing that LBE as a Subcontractor in the Bid. Unless an excusable error is found by the Director, a Bid that fails to document compliance with this requirement will be rejected as non-responsive. In addition, only LBEs that have been contacted and agreed to be listed as Subcontractors shall be credited toward meeting the LBE subcontracting participation requirements.
(D) Good Faith Outreach. In addition to meeting the LBE subcontracting participation requirements, Bidders on (1) Public Works/Construction Contracts that equal or exceed the Threshold Amount; and (2) Architect/Engineering, Professional Service, or General Services Contracts that equal or exceed the Minimum Competitive Amount shall undertake good faith outreach as set forth in this Section 14B.8(D) and duly promulgated Rules and Regulations to select Subcontractors to meet LBE subcontracting participation requirements. Except where a Contract does not include LBE subcontracting participation requirements or a Bid is exempt from good faith outreach under Section 14B.8(B), Bids from Bidders who fail to conduct and/or to document adequate good faith outreach steps as required by this Chapter 14B and its duly promulgated Rules and Regulations shall be declared non-responsive.
(E) Documentation of Good Faith Outreach. Each Bid that equals or exceeds the Threshold Amount or the Minimum Competitive Amount, as applicable, shall document good faith outreach and include the documentation with the Bid. Unless otherwise excused by this Chapter 14B, such documentation shall include: (1) the dollar amount of each subcontract and a statement of the scope of work to be performed under the subcontract; (2) the identification of each subcontract awarded to an LBE and, (3) for each subcontract, copies of the Subcontractor Bids submitted. Such documentation shall contain at least the Bid amount and a description of the scope of work, and separately, for each subcontract, a full and complete statement of the reason(s) for selection of the Subcontractor. If the reason is based on relative qualifications, the statement must address the particular qualifications at issue. If the reason is the Bid’s respective dollar amounts, the statement must state the amounts and describe the similarities and/or dissimilarities in the scope of work covered by the Bids. If no written Bids were submitted by some or all of the Subcontractors who bid the job, the Bidder shall submit a written statement containing (1) the amount of each oral Bid; and (2) separately, for each subcontract, a full and complete statement of the reason(s) for selection of the Subcontractor. Successful Bidders shall maintain the documentation described in this paragraph for three (3) years following completion of the Contract.
(Added by Ord. 92-06, File No. 050784, App. 5/11/2006; amended by Ord. 265-08, File No. 081231, App. 11/25/2008; Ord. 20-10, File No. 091405, App. 2/10/2010; Ord. 8-11, File No. 101006, App. 1/7/2011; Ord. 250-14
, File No. 140999, App. 12/17/2014, Eff. 1/16/2015, Oper. 7/1/2015; Ord. 203-21, File No. 210835, App. 11/12/2021, Eff. 12/13/2021, Oper. 7/1/2022)
CODIFICATION NOTE
(A) Prohibition on Discrimination. A Bidder may not discriminate in its selection of Subcontractors against any person on the basis of race, gender, or any other basis prohibited by law. The City Administrator shall work the Human Rights Commission to ensure that this provision is effected to the fullest extent allowed by law. Contract Awarding Authorities and the City Administrator shall refer all formal complaints of discrimination and all other instances where discrimination may have occurred of which they become aware to the Human Rights Commission for investigation and resolution pursuant to Administrative Code Chapter 12A and Section 14B.9(D).
(B) Availability Data. In order to prevent unlawful discrimination in the selection of subcontractors, and to identify and correct unlawful practices, the City will monitor the administration of City Contracts, including the selection of Subcontractors, as provided in this Section 14B.9. For Public Work/Construction, Architect/Engineering, Professional Services, and General Services Contracts which the Contract Awarding Authority reasonably anticipates will include Subcontractor participation, prior to the solicitation of Bids, the Director shall assemble data regarding the availability of MBEs, WBEs, and OBEs to provide work that is likely to be subcontracted. The Director, in the Director's sole discretion, shall determine the appropriate methodology.
(C) Requirements for Solicitations. In all solicitations of Public Work/Construction, Architect/Engineering, Professional Services, and General Services Contracts for which the Contract Awarding Authority reasonably anticipates will include Subcontractor participation, the Contract Awarding Authority shall include the availability data described above. Bidders shall undertake all required good faith efforts outreach steps in such a manner as to ensure that neither MBEs nor WBEs nor OBEs are unfairly or arbitrarily excluded from the required outreach.
(D) Review and Investigation by the Human Rights Commission. The Director of the Human Rights Commission may review or investigate any Bid, including the selection of the Bidder's Subcontractors, to determine whether discrimination may have occurred. The Director of the Human Rights Commission shall review Bids, during the bid protest period, to determine whether: (1) a potential Subcontractor or other person has filed a complaint of discrimination; (2) there is a significant difference between the percentages of MBEs, WBEs, or OBEs available to provide goods and services as Subcontractors on the Contract and the percentages of the Bidder's Subcontractors who are MBEs, WBEs, or OBEs; or (3) other facts and circumstances suggest that further inquiry is warranted. The Director of the Human Rights Commission, in the Director of the Human Rights Commission's sole discretion, shall determine whether and when to investigate further the conduct of a Bidder or Contractor.
(Added by Ord. 92-06, File No. 050784, App. 5/11/2006; amended by Ord. 250-14
, File No. 140999, App. 12/17/2014, Eff. 1/16/2015, Oper. 7/1/2015)
(A) City Administrator. In addition to the duties and powers given to the City Administrator elsewhere, the City Administrator or designee shall:
(1) When necessary, subpoena persons and records, books and documents for any hearing or investigation by the City Administrator or Director or audit pursuant to Section 14B.10(B)(5) concerning certification under, or compliance with this Chapter.
(2) Adopt rules and regulations establishing standards and procedures for effectively carrying out this Chapter.
(3) Issue forms for the Controller or Contract Awarding Authorities to collect information from Contractors as the City Administrator deems necessary to perform its duties under this Chapter.
(4) Hear appeals challenging certification denial decisions by the Director or the imposition of any sanction specified in Section 14B.17(D) against a Bidder, Contractor, Subcontractor, certified LBE, or applicant for certification.
(5) Direct Contract Awarding Authorities, departments and the Controller to provide to the Director such information as will be necessary to enable the Director to issue reports required by this Chapter to the Mayor and the Board of Supervisors, and otherwise to perform his/her duties imposed hereunder.
(B) CMD Director. In addition to the duties and powers given to the CMD Director elsewhere, the Director shall:
(1) Levy the same sanctions that a Contract Awarding Authority may levy as specified in Section 14B.17(D).
(2) Ensure that the necessary data concerning LBE, MBE, and OBE availability and participation in City Contracting is collected, analyzed, and included in CMD's annual report required by Section 14B.15(B). The Director shall identify areas of contracting where the City or any of its departments are failing to meet LBE subcontracting requirements or are contracting with MBEs, WBEs, or OBEs at rates less than would be anticipated by the availability data.
(3) Provide information and other assistance to LBEs to increase their ability to compete effectively for the award of City Contracts.
(5) In cooperation with the Controller, randomly audit at least three prime Contractors each fiscal year in order to insure their compliance with the provisions of this Chapter. The Director, in cooperation with the Controller, shall furthermore randomly audit 10 percent (10%) of the Joint Ventures granted Bid Discounts in each fiscal year.
(6) Take actions to ensure compliance with the provisions of this Chapter, including, without limitation, intervening in the selection process in the event of actual discrimination or harm, or issuing recommendations for selection processes administered directly by Contract Awarding Authorities to ensure that the minimum qualifications, evaluation criteria, or scoring methodologies set forth in the requests for bids, qualifications, or proposals, or the selection panel deliberations do not inadvertently disadvantage qualified Small-LBEs, Micro-LBEs, and MBEs, WBEs and OBEs, in competing for opportunities in City contracting.
(Added by Ord. 92-06, File No. 050784, App. 5/11/2006; amended by Ord. 250-14
, File No. 140999, App. 12/17/2014, Eff. 1/16/2015, Oper. 7/1/2015)
(A) In addition to the duties given to the Controller elsewhere, the Controller shall work cooperatively with the Director to provide such contractual encumbrance and payment data as the Director advises are necessary to monitor the participation of Small-LBEs, Micro-LBEs, MBEs, WBEs, and OBEs in City contracts. If any department refuses or fails to provide the required data to the Controller, the Controller shall immediately notify the Mayor, the Board of Supervisors, and the Director.
(B) The Controller shall not certify the award of any Contract subject to this Chapter where the Director has notified the Controller that the Contract Awarding Authority has not provided the information the Director advises is necessary under this Chapter.
(C) The Controller shall have the right to audit the books and records of Contractors, Joint Venture participants, and Subcontractors to ensure compliance with the provisions of this Chapter.
(Added by Ord. 92-06, File No. 050784, App. 5/11/2006; amended by Ord. 250-14
, File No. 140999, App. 12/17/2014, Eff. 1/16/2015, Oper. 7/1/2015)
In addition to the duties given to the Mayor elsewhere, the Mayor shall:
(A) By July 1st of each fiscal year, set and report to the Board of Supervisors a City-wide LBE Participation Goal on the overall dollar value of all Contracts projected to be awarded in the upcoming fiscal year that will be subject to this Chapter. The City-wide LBE Participation Goal shall be based on prior fiscal year LBE utilization data and current LBE availability, but shall not be less than forty percent (40%). The City-wide LBE Participation Goal shall include a sub-Goal of at least twenty percent (20%) participation by Micro-LBEs. Contract Awarding Authorities shall use, among other methods, the good faith efforts in Section 14B.7(A) to attain the City-wide LBE Participation Goal. The City-wide LBE Participation Goal may be achieved by Small and Micro LBE participation as a prime Contractor, Joint Venture partner, or Subcontractor.
(B) Issue notices to all City departments informing them of their duties under this Chapter. The notice shall contain the following information: (1) the City-wide LBE Participation Goal set in Section 14B.12(A) that all City departments are encouraged to attain during the fiscal year, and that a department's failure to attain the City-wide LBE Participation Goal shall be reported in CMD's annual report; (2) the availability of MBEs, WBEs, and OBEs to perform City contracting and that departments are expected to take all steps necessary to ensure against illegal or arbitrary discrimination or exclusion of any certified business; and (3) the data each department is required to provide the Controller on each contract award.
(C) Coordinate and enforce cooperation and compliance by all City Departments with this Chapter.
(Added by Ord. 92-06, File No. 050784, App. 5/11/2006; amended by Ord. 250-14
, File No. 140999, App. 12/17/2014, Eff. 1/16/2015, Oper. 7/1/2015)
Loading...